Judgment N.M. Jamdar, J. 1. This First Appeal filed by the Government of Maharashtra under Section 39 of Arbitration Act,1940 challenges the Judgment and Order dated 24.4.1992 passed by the Civil Judge, Senior Division, Pune passing a decree in respect of the Award of the Arbitrators appointed to resolve the disputes between the Appellants and the Respondent. The Award directed the Appellants to pay an amount of Rs.210.68 lakhs which included interest for the pre-reference period. Before the Civil Judge, the Appellants did not challenge this liability to pay the principal amount and restricted their challenge mainly to the grant of interest for the pre-reference period and other charges and interest thereupon. 2. The main question that needs to be considered in this Appeal is whether the Arbitrators as well as the learned Civil Judge were right in granting interest for the pre-reference period. Thus, only those facts which are relevant for the purpose of deciding the above question are encapsulated as under : 3. The Respondents-Plaintiffs were engaged in construction work of civil nature. The Respondents entered into a contract with the Irrigation Department of the Appellants for construction of Veer Baji Pasalkar Dam at village Varasgaon Taluka Velhe, District Pune. A work order in favour of the Respondents was issued on 6.10.1976. Dispute arose regarding payment to the Respondents and said dispute was referred for Arbitration to a panel of Arbitrators constituted by Government Resolution dated 10.4.1989. 4. The Arbitrators pronounced the Award on 11.9.1990 and as per the Award, the Appellants were directed to pay an amount of Rs.210.68 lacs towards final settlement of all the claims of the Respondents. This sum included an amount of Rs.58.18 lakhs towards interest for the pre-reference period. Award also contained a direction to pay an amount of Rs.2.03 lakhs towards bank guarantee commission The Award further directed the Appellants to pay the said amount to the Respondent within one month of the declaration of the Award failing which the Appellants were liable to pay interest at 18% interest p.a. from 16.10.1990 till the date of actual payment. 5. The Respondents filed a Special Civil Suit No.1109 of 1990 in the Court of Civil Judge, Senior Division, Pune with a prayer to file the Award and pass a decree in terms of the same. The Appellants filed a Misc. 5. The Respondents filed a Special Civil Suit No.1109 of 1990 in the Court of Civil Judge, Senior Division, Pune with a prayer to file the Award and pass a decree in terms of the same. The Appellants filed a Misc. Application No.672 of 1990 for setting aside the Award contending that the Arbitrators were not right in granting an amount of Rs.2.03 lacs towards bank guarantee commission and licence fees and that the Arbitrators were not right in granting an amount of Rs. 58.18 lacs towards the interest for the pre-reference period. The Appellants also prayed for setting aside the direction in the Award to pay further interest at 18% per annum. Appellants however, did not dispute the liability to pay the principal amount of Rs.150.47 lacs. 6. The Civil Judge, Senior Division, Pune heard both the Special Civil Suit as well as Misc. Application together and came to the conclusion that the Award of interest granted by the Arbitrators cannot be faulted with and further went on to hold that since the jurisdiction of the Court is limited while deciding objections to Arbitration Award, the findings of the Arbitrators cannot be interfered with. The learned Civil Judge accordingly, dismissed the Misc. Application No.672 of 1990 filed by the Appellants and decreed Special Civil Suit No. 1109 of 1990 directing the appellants to pay an amount of Rs.60.21 lacs in terms of the award along with interest. Being aggrieved, the Appellant-State has brought this First Appeal before us under section 39 of the Arbitration Act, 1940. 7. We have heard Mrs. Geeta Mulekar, learned Assistant Government Pleader for the State and Mr. A.V. Anturkar learned counsel for the Respondents. 8. The primary contention raised by the learned Assistant Government Pleader is that the interest for pre-reference period ought not to have been granted by the Arbitrators as that issue was not specifically referred for arbitration and the Arbitrators did not have the power to grant interest for the pre-reference period. A.V. Anturkar learned counsel for the Respondents. 8. The primary contention raised by the learned Assistant Government Pleader is that the interest for pre-reference period ought not to have been granted by the Arbitrators as that issue was not specifically referred for arbitration and the Arbitrators did not have the power to grant interest for the pre-reference period. It was further contended that in view of the law laid down by the Apex Court in the case of DURGA RAM PRASAD VS.GOVERNMENT OF A.P. reported in (1995) 1 SUPREME COURT CASES 418 there was clear legal error on the part of the Arbitrators to grant interest for the pre-reference period which amounted to 'misconduct' and thus the Award to that effect ought to have been set aside by the learned Civil Judge. 9. Mr. Anturkar, learned counsel for the Respondent on the other hand submitted that the Arbitrators were well within their powers to grant interest for the pre-reference period as according to him as per the terms of the Agreement as well as the Reference, the Arbitrators were empowered to do so. He further contended that the Respondents had not given up their claim towards grant of interest for pre-reference period which was implicit in their demand. He also contended that the scope of the Civil Court and this Court to interfere with the award of the arbitrators mutually agreed by the parties, is limited and no case is made out by the Appellants for invoking this limited jurisdiction. 10. The first question that needs to be addressed is whether the issue of grant of interest for the pre-reference period was referred to Arbitrators. If the said issue was not referred to Arbitrators then the Arbitrators could not have traveled beyond the scope of the Reference. For that purpose, it is necessary to first advert to the claim of the Respondent as noticed from the Arbitration Award. Claim No.1: Claim amounting to Rs.566.69 lakhs on account of under utilization of machinery and infra-structure owing to extended construction period together with interest at 18 percent per annum compounded quarterly amounting to Rs.441.26 lakhs adding up to a total amount of claim of Rs.1007.95 lakhs. Claim No.1: Claim amounting to Rs.566.69 lakhs on account of under utilization of machinery and infra-structure owing to extended construction period together with interest at 18 percent per annum compounded quarterly amounting to Rs.441.26 lakhs adding up to a total amount of claim of Rs.1007.95 lakhs. Claim No.2: Claim amounting to Rs.32.59 lakhs on account of incorrect deduction of 2 ½ percent of the value of bills made for discount for timely payments together with interest thereon at 18 percent per annum compounded quarterly amounting to Rs.95.66 adding up to Rs.128.25 lakhs. Claim no.3: The claimants also have requested the Arbitrators to award the incidental claim of the cost of this arbitration to them. 11. The Arbitrators framed questions which they were called upon to decide in the Arbitration proceedings. The questions so framed are reproduced as under : (i) Is it correct that the Claimants did not prove that they had all requirements of adequate progress and in fact according to the Respondents, did not possess it during the initial period of contract up to 5-10-82 ? (ii) Is it correct that the performance of the contract by Claimants not being adequate in the original period of contract the performance spilled over period of financial stringency and cement shortage and other difficulties thereafter ? (iii) Is it correct that Claimants were prevented from expected performance under this contract because of lack of engineering decisions in the initial period, cement shortages over years, non-payment of bills because of financial stringency of the Government, non payment of large amounts of claims etc ? (iv) In the light of the above questions whether the Claimants should shoulder the burden of responsibility for the delayed performance and in what proportion ? It is clear from the above mentioned claims as well as questions framed that there is no specific issue regarding grant of interest for the pre-reference period for adjudication. Furthermore, in the claim statement, no period for the claim of interest has been specifically mentioned. The Appellant in para 23 of its Written Statement before the Arbitrators categorically stated that the claim for interest for the pre-reference period was not referred to the arbitration. 12. Interest for the pre-reference period has to be specifically prayed for and claimed. Furthermore, the claim for interest for the pre-reference period has to be specifically referred for Arbitration. The Appellant in para 23 of its Written Statement before the Arbitrators categorically stated that the claim for interest for the pre-reference period was not referred to the arbitration. 12. Interest for the pre-reference period has to be specifically prayed for and claimed. Furthermore, the claim for interest for the pre-reference period has to be specifically referred for Arbitration. If the said issue is not referred to the Arbitrators for consideration then the Arbitrators will have no jurisdiction to grant the same. If the Arbitrators have granted relief to any party, which they had no jurisdiction to grant, then they would commit a legal error that will go to the root of the matter. 13. It will be relevant to note section 30 of the Arbitration Act, 1940. 30. Grounds for setting aside award: An award shall not be set aside except on one or more of the following grounds namely: (a) that an arbitrator or umpire has misconducted himself or the proceedings. b) that an award has been made after the issue of an order by the court superseding the arbitration or after arbitration proceedings have become invalid under Sec.35; (c) that an award has been improperly procured or is otherwise invalid. 14. One of the grounds for setting aside the Arbitration Award is that the Arbitrators have 'misconducted' themselves. It is now settled that the phrase 'misconduct' employed in section 30 (a) encompasses 'legal misconduct' as well. Grant of any relief which has not been specifically referred for Arbitration will clearly fall within the ambit of the phrase 'misconduct' as envisaged under section 30 (a) of the Arbitration Act of 1940. Thus, the learned Civil Judge was in error in not setting aside the Award in respect of the interest for pre-reference period and the further interest thereupon. Thus the Appellant has made out a clear case for exercising powers under section 39 of the Arbitration Act, 1940. 15. There is one more point on which this ground must be held in favour of the Appellant. The learned Assistant Government Pleader has drawn our attention to the term in the Agreement between the parties in respect of claim of interest. 15. There is one more point on which this ground must be held in favour of the Appellant. The learned Assistant Government Pleader has drawn our attention to the term in the Agreement between the parties in respect of claim of interest. The said term is as under : NO INTEREST ON MONEY DUE TO THE CONTRACTOR: No omission by the Engineer to pay the amount due upon measurements or otherwise shall vitiate or make void the contract, nor shall the contractor be entitled to interest on any guarantee bond or payment in arrears not on any balance which may on the final settlement of his account be found due to him. 16. In the context of this term, the learned Assistant Government Pleader relied on the judgment of the Apex Court in DURGA RAMPRASAD VS GOVERNMENT OF A.P. REPORTED in (1995) 1 SCC 418 . In that case the term regarding interest in the Agreement between the parties was as under : 69.” Interest on money due to the Contractor. (a) No omission by the Executive Engineer or the Sub-Divisional Officer to pay the amount due upon certificates shall vitiate or make void the contract nor shall the contractor be entitled to interest upon any guarantee found or payments in arrears nor upon any balance which may on the final settlement of his accounts be found to be due to him.” 17. The terms regarding interest in the case before the Apex court and case at hand are identical. The Apex court in the case of DURGA RAM PRASAD supra considered the implications of the above term as to whether the contractor was entitled to grant of pre-reference period on the basis of such term. The Apex court observed as under : 4. It is true that the learned Single Judge of the A.P. High Court appears to have considered the question and the construction of clause 69 was put up is in favour of the contractor as contended for. It is not a correct approach. The construction put up on clause 69 of MDSS is not correct. However on the facts in that case there does not appear to any dispute as to the amount due. It is not a correct approach. The construction put up on clause 69 of MDSS is not correct. However on the facts in that case there does not appear to any dispute as to the amount due. Therefore the learned Judge had proceeded that since the contract provides for withholding the payment for a suspended period of six months, if the amount is withheld beyond that period, the contractor would be entitled to payment of interest. That is not the factual scenario in this case. The very dispute is whether the appellant is entitled to the payment of the amount pursuant to the contract. The claim of the State appears to be that the appellant had not constructed the godown in accordance with the specification is and that therefore they withheld the payment. Unless the dispute is resolved and that the amount is found due, the contractor is not entitled to the payment of it. Thereon interest in terms of clause 69 of the MDSS is contracted out. When such be the position, then mere reference does give jurisdiction to the arbitrator to award interest to the period prior to the reference. 5. This Court in Executive Engineer (Irrigation) vs. Abhaduta Jena (in SCC pg 435 para 20) held that : “In the remaining cases which arose before the commencement of the Interest Act, 1978 the respondents are not entitled to claim interest either before the commencement of the proceedings. They are not entitled to claim interest for the period prior to the commencement of the arbitration proceedings for the reason that the Interest Act 1939 does not apply to their cases and there is no agreement to pay interest or any usage of trade having the force of law or any other provisions of law under which the claimants were entitled to recover interest”. This ratio was followed by another Bench of this court in State of Orissa vs. Niranjan Swain. In Secy. Irrigation Dept vs. G.C. Roy the constitution bench was concerned with the case whether the contractor is entitled to interest pendente lite. The controversy therefore centres around the question whether the contractor is entitled to the interest pendente lite. The ratio therein therefore has no relevance for the purpose of this case. The ratio in Jena case on the above quoted ratio is still good law. The controversy therefore centres around the question whether the contractor is entitled to the interest pendente lite. The ratio therein therefore has no relevance for the purpose of this case. The ratio in Jena case on the above quoted ratio is still good law. Accordingly, we are of the view that the contractor is not entitled to payment of interest in terms of clause 69 of MDSS for the period anterior to the reference for arbitration until the final settlement of the amount due to the contractor of his account is determined. In this case that dispute was determined by the arbitrator in his award. Therefore, from the date of withholding till the date of award the appellant is not entitled to the payment of interest. The arbitrator has no jurisdiction to arbitrate that dispute. The Division Bench therefore, rightly negatived the claim of interest.” 18. The ratio of the above mentioned case is directly applicable to the case before us. On the interpretation of almost exactly the same term the Apex court came to the conclusion that such term does not entitle the contractor for grant of interest for the pre-reference period. A term with such phraseology is commonly found in the government contracts. Once the term with very same phraseology and purport has already been interpreted to mean that the contractor shall not be entitled to grant of interest for pre-reference period, the Award made by the Arbitrators in respect of grant of interest for pre-reference period must be quashed and set aside. Grant of such interest was thus beyond the jurisdiction of the Arbitrators which has resulted in 'misconduct' and the learned Civil Judge fell in error in not setting aside the Award to that effect. Thus, we set aside the grant of amount of Rs.58.18 lacs as interest for the pre-reference period. Further the relief of grant of interest on the amount of Rs.58.18 lacs (interest for pre-reference period) has to be set aside being consequence of the preceding direction. 19. The learned AGP further submitted that grant of Rs.2.03 lacs in respect of bank guarantee commission and other charges by both the Arbitrators as well as the learned Judge was not proper. According to her, as per the contract it was the responsibility of the respondents to incur those charges. In this regard, clause 10 of the contract needs to be noticed. According to her, as per the contract it was the responsibility of the respondents to incur those charges. In this regard, clause 10 of the contract needs to be noticed. It is reproduced as under : 10.0 Security Deposit: 10.1. A sum as mentioned in 2-2 tender form at para (d) (i) will have to be deposited by the contractor at the time of completing the tender documents, if his tender is proposed to be accepted by government. 10.2 In lieu of cash deposit mentioned above, Government securities, guarantee bonds in prescribed form of nationalized Banks or schedule Banks, National saving certificates, Post office cash certificates, National Plan saving Certificates, National Defence Saving Certificates etc and as may be approved by government from time to time, standing to the name of the tenderer shall be accepted if pledged as security deposit in the name of the Executive Engineer, Khadakwasla Canal Division no.1 Poona-1. 10.3. In addition to the sum as in 10.1 and 10.2 above, sums as security deposit will be deducted from running account bills, at the rate shown at (e) in B-2 Tender Form to a total up to a sum mentioned at (d) (ii) in the B-2 Tender form. The cash recovery of security deposit made from the running account bills, will remain in the form of cash or government securities, National saving certificates, Post office cash certificates, National Plan saving certificates, National Defence saving certificates, or as may be approved by government from time to time. Standing in the name of the tenderer and pledged as security deposit in the name of Executive Engineer, Khadakwasla Canal Division No.1 Poona-1. 10.4. As a concession, contractor is allowed to pay security deposit in the form of Bank guarantee vide col.10.10.2 above on the express condition that if due to unforeseen circumstances, government is forced to abandon the execution of work after the signing of the contract or during the currency of contract the initial bank commission charges paid by the contractor for obtaining the guarantees will not be refunded to the contractor.” Clause 10.1 makes it clear that as a first priority, the respondent was required to give security deposit in cash as mentioned in the tender form at para D (d) (i). As per clause 10.2 the respondent was permitted tender in lieu of cash deposit; government securities, guarantee bonds in the prescribed form of Nationalised Banks or scheduled banks and so on. The option of providing bank guarantee instead of cash was to be exercised by the Respondents. The Respondent exercised the option of providing a bank guarantee. Furthermore, the wording of the clause 10.4 would indicate that tendering security deposit by way of bank guarantee was a concession to be accorded to the respondent under the Contract. The learned AGP was right in contending that the Appellants cannot be made responsible for the choice exercised by the Respondents in providing bank guarantee instead of cash. She would contend that in fact since the respondent chose to give bank guarantee the Appellant lost interest on the amount which it would have earned if cash deposit was made. In our opinion, there was no justification to saddle the Appellants with an amount of Rs.2.03 lacs towards bank guarantee commission which was incurred due to the option exercised by the Respondent for its own convenience. Except referring to this argument, we find no satisfactory discussion regarding the same in the impugned judgment. Saddling a party with an amount which is clearly the responsibility of another party under the contract, is according to us, a fundamental error on the part of Arbitrators which would fall within the ambit of section 30 of the Arbitration Act, 1940. Thus, the award and the decree to this extent also requires to be set aside. 20. Accordingly, the Appeal is allowed. The Judgment and Decree is set aside and the Misc. Application No.672 of 1990 is allowed. Appeal is allowed in above terms.