Research › Search › Judgment

Bombay High Court · body

2023 DIGILAW 149 (BOM)

Kamlakar Motiram Satve v. State Of Maharashtra

2023-01-11

S.V.GANGAPURWALA, SANDEEP V.MARNE

body2023
JUDGMENT SANDEEP V.MARNE,J. - These three Public Interest Litigations involve the issue of development of vast lands at Powai in Mumbai known as "Powai Area Development Scheme" (for short PADS). The constructions put up by the developer on these lands under PADS have been challenged in these three Public Interest Litigations praying inter alia for institution of inquiry in respect of Tripartite Agreement dtd. 19/11/1986 executed between State of Maharashtra, Mumbai Metropolitan Region Development Authority (MMRDA) and the developers. 2. Extensive interim order dtd. 22/2/2012 came to be passed in the present Public Interest Litigations holding that there was breach and non-compliance of the Tripartite Agreement by the developers. This court therefore proceeded to pass the following directions: (a) The petitioners and the developer as also the Metropolitan Commissioner of the MMRDA shall prepare a statement of all the buildings and structures put up by the developer in the Powai ADS alongside their names and description and the numbers and area of the units/flats therein within 4 weeks from today. (b) The petitioners, the developer and the Metropolitan Commissioner of the MMRDA shall prepare a plan showing the vacant areas of the plot under the Powai ADS, where further buildings may be constructed, within 4 weeks from today. (c) If the parties are unable to work jointly they would be entitled to work individually in terms of (a) and (b) above. (d) The developer shall not put up any further construction of whatsoever nature on the remainder of the plot under the Powai ADS before specifying the vacant lands and the buildings that can be constructed thereupon as per the statement and plan mentioned in clauses (a) and (b) above and shown to Court. (e) The developer shall be entitled to commence any further construction only after obtaining the specific permission of this Court in that behalf and subject to the sanctioned plans of the MMC. (f) Such construction shall be only of 1511 flats of 40 sq.mtrs 1593 flats of 80 sq.mtrs without any amalgamation, exception, or further allowance. (g) No two flats shall be sold to the same person or any member of her/his family, being her/his spouse and children. (h) The developer shall sell to the State Government from such construction such of the flats or units as would represent 15% of the total FSI of the total plot consumed under the development @ Rs.135.00 per sq.ft. (g) No two flats shall be sold to the same person or any member of her/his family, being her/his spouse and children. (h) The developer shall sell to the State Government from such construction such of the flats or units as would represent 15% of the total FSI of the total plot consumed under the development @ Rs.135.00 per sq.ft. And the State Government shall offer those flats to be purchased by the employees of the State Government at the aforesaid rate in a transparent manner. (i) After constructing and showing the Court the total number of units or flats constructed for residential purpose as initially required under the Powai ADS and after offering to sell the flats as directed in clause (h) above, the developer shall submit a report of such construction and sale to Court with a copy to the Petitioners in all the above Petitions, the MMRDA, the State Government and the MMC. (j) The Developer shall thereafter be entitled to put any further construction as per law. (k) The compensation for the breaches of the tripartite agreement claimed by the MMRDA shall be determined in the appropriate forum. (l) The petitioners may file any private criminal complaint for any offence committed by the developer or any of the public officers of MMRDA or the State Government in the appropriate Court. (m) All the writ petitions shall stand over to 29/3/2012 for placing on record the statement and plan as directed in clauses (a) and (b). 3. Thus under the interim order dtd. 22/2/2012, this court directed the developers/applicants to complete construction of 1511 flats of 40 sq.mtrs, 1593 flats of 80 sq.mtrs and to sell to the State Government such of the flats or units as would represent 15% of the total FSI of the total plot consumed under the development. 4. Further interim order came to be passed by this court on 3/10/2017 clarifying that the number of flats to be constructed by the developer would be 1511 flats of 40 sq.mtrs and 887 flats of 80 sq.mtrs. A timeline came to be set by this court for completion of construction of such 1511 flats of 40 sq.mtrs and 887 flats of 80 sq.mtrs. A timeline came to be set by this court for completion of construction of such 1511 flats of 40 sq.mtrs and 887 flats of 80 sq.mtrs. In paragraph 22 of the order, this court directed that in the event of the developers/applicants failing to comply with any of the terms and conditions laid down in the order, they would construct additional 10% of the remaining flats to be constructed which remained incomplete as on 1/6/2021. 5. The Interim Application no. 10155 of 2022 has been filed by the developers/applicants seeking condonation of delay with the following prayers: (a) that this Hon'ble Court be pleased to condone the delay by extending time for completing the construction of 'A' and 'B' wings and 'C' wing of Atlantis building comprising of 448 number of flats of 80 sq. mtrs to March 2018 and February 2019 respectively. (b) that this Hon'ble Court be pleased to extend the timelines for completing the construction of: i. 'C' and 'D' Wings of Building Castle Rock till 30/6/2021 and 'A' and 'B' Wings of Building Castle Rock till 30/1/2022 (instead of December, 2020); ii. the Building Regent Hill, Wings A and B, C, D and E till 30/1/2023 (instead of 31/5/2021); iii. the Building Sorrento till 15/6/2023 (instead of December, 2020); (c) for interim and ad-interim relief in terms of prayers (a) and (b) above; (d) for such other and consequential reliefs as this Hon'ble Court may deem fit; and 6. When the Interim Application no. 10155 of 2022 came up before this court on 9/4/2021, this court passed following order : I In so far as prayer (a) is concerned, the same stands deferred for consideration at a later stage. II We allow the prayer clauses (b)(i) and (b)(ii). III In so far as prayer (b)(iii) is concerned, the applicants shall file a better affidavit explaining the reasons for the delay in commencement of construction. IV All other conditions imposed by the earlier orders of this Court shall remain intact. V The Interim Application shall be listed once again on 9/6/2021. 7. Thus prayer clause (b)(i) and (b)(ii) of the Interim Application were allowed and while prayer clause (a) was deferred for consideration at a later stage, the developers /applicants were granted liberty to file better affidavit with regard to prayer clause (b)(iii). Accordingly, the developers/applicants have filed affidavit dtd. V The Interim Application shall be listed once again on 9/6/2021. 7. Thus prayer clause (b)(i) and (b)(ii) of the Interim Application were allowed and while prayer clause (a) was deferred for consideration at a later stage, the developers /applicants were granted liberty to file better affidavit with regard to prayer clause (b)(iii). Accordingly, the developers/applicants have filed affidavit dtd. 7/6/2021 setting forth the reasons for delay in construction of flats in the building 'Sorrento' covered by prayer clause (b)(iii). Further affidavit dtd. 19/1/2022, 21/3/2022 and 22/6/2022 have been filed by the developers/applicants putting on record progress made by them with regard to construction of flats from time to time. 8. In the affidavit dtd. 22/3/2002, the developers/applicants have put on record that the entire construction is now complete and the obligation imposed by the interim order dtd. 22/2/2022 read with the order dtd. 3/10/2017 have been met with. It is stated that the developers have completed construction of 1511 flats of 80 sq.mtrs and 1593 units of 40 sq. mtrs and have further handed over 128 flats of 40 sq. mtrs and 128 flats of 80 sq.mtrs to the State Government on 7/5/2022. 9. After consideration of the above affidavits, this court constituted a three member committee to verify completion of construction of 1109 flats of 40 sq.mtrs and 276 flats of 80 sq. mtrs by its order dtd. 19/10/2022. The committee appointed by this court submitted its report dtd. 1/11/2022 confirming completion of construction of 1109 flats of 40 sq. mtrs and 276 flats of 80 sq.mtrs. 10. Thus as of now the updated status of construction of the flats by the developers is as follows:- 11. Thus, as against direction of this court in interim orders dtd. 22/2/2012 and 3/10/2017 for construction of 887 flats of 80 sq.mtrs, the developer/applicants have constructed 1150 flats of 80 sq. mtrs. However there appears to be delay in construction of some of the flats. It is evident from the above chart showing updated status of construction. So far as 'A' and 'B' wings of 'Atlantis' building is concerned, 294 flats of 80 sq.mtrs which were required to be constructed by December 2017 are constructed by 28/3/2018. In 'C' wing of 'Atlantis' building 154 flats of 80 sq. mtrs which were supposed to be complete by June 2018 are constructed by 13/2/2019. So far as 'A' and 'B' wings of 'Atlantis' building is concerned, 294 flats of 80 sq.mtrs which were required to be constructed by December 2017 are constructed by 28/3/2018. In 'C' wing of 'Atlantis' building 154 flats of 80 sq. mtrs which were supposed to be complete by June 2018 are constructed by 13/2/2019. These flats are covered in prayer clause (a) of the Interim Application no. 10155 of 2022 which was deferred by this court by its order dtd. 9/4/2021. So far as 88 flats of 40 sq. mtrs in building 'Sorrento' are concerned, the same were required to be completed by December 2020. However, the same appears to have been constructed by 13/6/2022. These flats are covered by prayer clause (b)(iii) of the Interim Application for which developers/applicants were granted liberty to file better affidavit by order dtd. 9/4/2021. 12. We have heard Dr. Sathe, the learned Senior Advocate assisted by Mr. Chetan Kapadia for the developers/applicants. Mr. Sathe would take us through the affidavits explaining the reasons for delay in construction of some of the flats. He would submit that the delay caused in construction of some of the flats in the building 'Sorrento' was essentially on account of the requirement of obtaining environmental clearances, which was beyond the control of the developers. That the entire obligation of construction of requisite number of flats and handing over of requisite area to the State Government being met by the Developers, they should now be permitted to proceed further with the development of PADS by lifting all fetters imposed by this court in its various interim orders. He would further submit that the bonafides of the developers are clear from the fact that they have developed additional flats of 80 sq. mtrs than the one required under the interim orders of this Court. Dr. Sathe would further contend that as directed by this court in paragraph 53(g) of the interim order dtd. 22/2/2012 developers have scrupulously followed the conditions of not selling two flats to the same person or any member of her/his family, being her/his spouse and children. 13. mtrs than the one required under the interim orders of this Court. Dr. Sathe would further contend that as directed by this court in paragraph 53(g) of the interim order dtd. 22/2/2012 developers have scrupulously followed the conditions of not selling two flats to the same person or any member of her/his family, being her/his spouse and children. 13. Mr Joshi, the learned counsel appearing for the Petitioner in PIL/21/2010 would oppose the prayers in the Interim Application filed by the developers contending that the justification of delay in obtaining environment clearance for construction of the building 'Sorrento' is required to be rejected as the developers always had the knowledge about mandatory requirement of law for obtaining environmental clearance. He would submit that on account of inordinate delay in construction of 88 flats of 40 sq.mtrs in building 'Sorrento', the direction in paragraph 22 of the interim order dtd. 22/8/2017 for construction of additional 10% flats would automatically kick in. He would therefore urge before us to direct further construction of 10% additional flats of 80 sq. mrts. by the developers. 14. We have also heard Mr. Kakade, the learned Government Pleader who draws our attention to the affidavit dtd. 19/9/2022 in which the State Government has also clarified that the developers/applicants have complied with all the obligations. We would refer to the relevant paragraphs of the affidavit dtd. 19/9/2022 in which it is averred in paragraph 6 to 8 as under: 6. On 7/5/2022, the Respondent No. 2, MMRDA has taken possession of 128 flats of 40 sq. mtrs and 128 flats of 80 sq.mtrs having area aggregating 17,173.70 sq.mtrs against 17,146.05 sq.mts in the Hill Grange Building. Hereto annexed and marked Exhibit "A" and "A-1" is copy of the said Possession Receipt dtd. 7/5/2022 along with the English translation. 7. Thus, the Applicant has complied with the obligation of handing over 17,146.05 sq.mtrs to State Government as specified in paragraph 53(h) of the said Judgment dtd. 22/2/2012 read with the paragraph (3) of the Order dtd. 3/10/2017. 8. Thus, the Applicants have complied with the paragraph no. 53 (f) of the said Judgment dtd. 22/2/2012 read with paragraph no. 16 of the Order dtd. 3/10/2017 in respect of construction of 40 sq.mtrs and 80 sq.mtrs flats. 15. We have also heard Mr. 22/2/2012 read with the paragraph (3) of the Order dtd. 3/10/2017. 8. Thus, the Applicants have complied with the paragraph no. 53 (f) of the said Judgment dtd. 22/2/2012 read with paragraph no. 16 of the Order dtd. 3/10/2017 in respect of construction of 40 sq.mtrs and 80 sq.mtrs flats. 15. We have also heard Mr. Shinde, the learned counsel for MMRDA who also does not dispute fulfillment of obligations under the interim orders of this Court by the developers/applicants. 16. Having heard the learned counsels for rival parties and after perusal of previous orders passed by this court and various affidavits filed by the parties, the undisputed position that emerges is that the developers/applicants have fulfilled the entire obligations cast upon them by this Court by its interim orders. However they have defaulted in respect of timeline with regard to construction of some of the flats as detailed above. This court has already granted prayer clauses b(i) and b(ii) of the Interim Application No. 10155 of 2022 and has thereby extended the timeline in respect of some the flats in buildings 'Castle Rock' and 'Regent Hill' to 30/1/2022 (instead of December, 2020) and 30/1/2023 (instead of 31/5/2021) respectively. What remains now is to extend the timeline/ condone the delay in construction of some of the flats in buildings 'Atlantis' and 'Sorrento'. 17. In the affidavit dtd. 7/6/2021, the developers/applicants have provided justification for delay in construction of flats in building 'Sorrento' covered by prayer clause (b)(iii). We have gone through the affidavit dtd. 7/6/2021. It appears that the developers/applicants had obtained Environment Clearance on 10/4/2014 in respect of other buildings such as Atlantis, Mapple and Hill Grange and since 'Sorrento' was newly proposed after the year 2014, the earlier Environment Clearance of 2014 did not apparently cover it. Therefore a common application for environment clearance was made to the Central Government on 3/8/2017 for proposed expansion of residential buildings (including Sorrento) and on account of non-convening of meeting of Expert Appraisal Committee, the application remained pending. Due to change in the policy of grant of EC by the State Environment Assessment Committee, developers/applicants were required to re-apply for EC on 17/5/2018 at the State Government level. 18. The State Expert Appraisal Committee (SEAC II) in its 77th meeting held on 16/11/2018 considered developers'/applicants' application but decided to defer the same seeking certain clarifications. Due to change in the policy of grant of EC by the State Environment Assessment Committee, developers/applicants were required to re-apply for EC on 17/5/2018 at the State Government level. 18. The State Expert Appraisal Committee (SEAC II) in its 77th meeting held on 16/11/2018 considered developers'/applicants' application but decided to defer the same seeking certain clarifications. The clarifications were provided by the developers on 6/12/2018. Thereafter in various meetings of SEAC II the proposal was deferred for various reasons, details of which are stated in the affidavit. Ultimately SEAC recommended the proposal to State Environment Impact Assessment Authority (SEIAA) for approval on 24/2/2019. SEIAA granted environment clearance to the developers/applicants on 29/5/2019 subject to conditions. This is how final environment clearance came to be granted in respect of various buildings including Sorrento on 14/6/2019. The affidavit dtd. 7/6/2021 also states the reason of delay in issuance of NOC for tree cutting resulted in delay in issuance of Commencement Certificate from 31/8/2018 to 6/3/2019. Another reason cited is sub division of plot-layout as per condition 10 of the IOD which consumed time between 20/11/2018 to 5/7/2019. Last impediment cited is about the ambiguity regarding applicability of Development Control & Promotion Regulations, 2034 and its effect requiring amendment of layout and plans. 19. For the above quoted reasons delay, in completion of 88 flats of 40 sq.mtrs in building Sorrento is sought to be justified. It must however be noted here that in prayer clause (b)(iii), the developers/applicants sought extension of time upto 15/6/2023 for completion of those flats, whereas they were able to complete construction of the building 'Sorrento' on 13/6/2022 itself, i.e. before the extension sought. 20. Having gone through the reasons set forth in the affidavit dtd. 7/6/2021 with regard to delay in construction of 88 flats of 40 sq.mtrs in building 'Sorrento', we record our satisfaction about the justification given therein. Therefore we are of the view that prayer clause b(iii) sought for in the Interim Application No. 10155 of 2022 deserves to be granted. 21. In additional affidavits filed on 19/1/2022, 22/3/2022 and 22/6/2022, the developers/applicants have put on record as to how the construction progressed and how ultimately the entire obligations of construction of both categories of flats were finally completed by them. 22. 21. In additional affidavits filed on 19/1/2022, 22/3/2022 and 22/6/2022, the developers/applicants have put on record as to how the construction progressed and how ultimately the entire obligations of construction of both categories of flats were finally completed by them. 22. So far as prayer clause(a) of the Interim Application No. 10155 of 2022 is concerned, the delay in construction of 294 flats of 80 sq.mtrs in 'A' and 'B' wing of building 'Atlantis' is only of three months. They were to be constructed by December 2017, but have been constructed by 28/3/2018. So far as 154 flats of 80 sq.mtrs in 'C' wing of building 'Atlantis' is concerned, again the delay is about seven and a half months. They were to be constructed by June 2018 and are actually constructed by 13/2/2019. Since the delay in construction of flats covered by prayer clause (a) of the Interim Application is not significant, we propose to condone the same. It must be observed here that under the interim orders of this court, the developers/applicants were under obligation to construct only 887 flats of 80 sq.mtrs whereas they have constructed 1150 flats of 80 sq.mtrs i.e more than the obligation casted by this court. This is yet another factor to be borne in mind while considering the prayer of the developers/applicants for condonation of delay in respect of flats covered by prayer clause (a) of the Interim Application. 23. As observed above, this court has already granted prayer clause (b)(i) and b(ii) of the Interim Application. As observed above we are inclined to grant prayer clauses (a) and (b)(iii) of the Interim Application No. 10155 of 2022. 24. Interim Application No. 10110 of 2022 has been filed seeking direction to transfer the amount of Rs.112.35 cores (approx.) presently lying in the joint account held in the names of Applicants (Classique Associates and HGP Community Pvt. Ltd.) and the Prothonotary and Senior Master of this court into the bank account maintainable by the applicants in accordance with the provision of the Real Estate (Regulation and Development) Act, 2016 in respect of building 'Regent Hill' to be utilised for the purpose of construction of the building. Prayer is also made to deposit the considerations received by the developers/applicants from sale of the balance flats into their bank accounts. Prayer is also made to deposit the considerations received by the developers/applicants from sale of the balance flats into their bank accounts. Now that interim orders of this court are already satisfied by the developer/applicants, the sale proceeds deposited as per interim order dtd. 3/10/2017 lying in the above joint accounts can be permitted to be withdrawn by the applicants (Classique Associates and HGP Community Pvt. Ltd.). Thus the Interim Application No. 10110 of 2022 can also be disposed of permitting withdrawal of such amounts. 25. While hearing the Interim Application nos. 10155 of 2022 and 10110 of 2022, it is noticed that the main Public Interest Litgations have not yet been disposed of. By the initial extensive interim order though this court issued various directions in the main PILs, the same were adjourned to 19/3/2012 seeking compliance. Thereafter various interim orders appear to have been passed in the PILs. However all the three PIL Nos. 131 of 2008, 91 of 2008 and 21 of 2010 continue to remain pending. The aspect of violation of Tripartite Agreement on the part of the developers, which is the main issue in all there PILs, has already been dealt with in the interim order dtd. 22/2/2012 and corrective measures were directed to be undertaken. Thus the main issue involved in the PILs has already been decided by the interim order dtd. 22/2/2012. With complete compliance of all obligations put on the developers/applicants for construction of flats and handing over tenements to the State Government, we observe that no purpose would be served in keeping the PILs pending any further. Therefore while disposing of the Interim Application No. 10155 of 2022 and 10110 of 2022, we propose to dispose of the main PILs as well. Accordingly, we proceed to pass the following order : ORDER (i) Interim Application No. 10155 of 2022 is allowed in terms of prayer clause (a) and (b)(iii) as well. (ii) Delay in construction of some of the flats as per the directives of this court in the interim order dtd. 22/2/2012 and 3/10/2017 shall stand condoned. (iii) It is recorded that the developers/applicants have completed construction of 1511 flats of 40 sq.mtrs and 887 flats of 80 sq.mtrs as envisaged in the interim orders dtd. 22/2/2012 and 3/10/2017. (ii) Delay in construction of some of the flats as per the directives of this court in the interim order dtd. 22/2/2012 and 3/10/2017 shall stand condoned. (iii) It is recorded that the developers/applicants have completed construction of 1511 flats of 40 sq.mtrs and 887 flats of 80 sq.mtrs as envisaged in the interim orders dtd. 22/2/2012 and 3/10/2017. (iv) It is further recorded that the flats having aggregate area of 17146.05 sq.mtrs have been handed over by the developers/ applicants to MMRDA which has issued possession receipt dtd. 7/5/2022. (v) In view of compliance of all the obligations imposed on the developers/applicants by interim order dtd. 22/2/2012 and 3/10/2017, all restraints imposed in paragraph 53 of the order dtd. 22/2/2012 are vacated and the developer/applicants shall be at liberty to proceed with development of PADs land without any embargo/restrictions including regarding size of tenements or joint use of the tenements, amalgamation or construction of tenements for commercial use. (vi) The amounts of sale proceeds deposited as per order dtd. 3/10/2017 lying in the joint accounts held jointly by applicants (Classique Associates and HGP Community Pvt. Ltd.) and Prothonotary and Senior Master of this court along with interest accrued thereof are permitted to be withdrawn by the joint applicants and the Prothonotary and Senior Master is directed to take steps to close the joint accounts. As a result, Interim Application No. 10110 of 2022 seeking withdrawal of the amounts stands disposed of. (vii) The one-man committee headed by Justice S. Radhakrishnan (Retired) appointed by this court by order dtd. 3/10/2017 shall stand discharged. (viii) It is made clear that all other directions given in the interim order dtd. 22/2/2012 and 3/10/2017, except as modified by the present judgment, shall continue to operate. (ix) Public Interest Litigation Nos. 131 of 2008, 91 of 2008 and 21 of 2010 stands disposed of. (x) In view of the disposal of the Public Interest Litigations all Interim Applications, Civil Applications and Notices of Motion stand disposed of. (xi) There shall be no orders as to costs.