MJD Construction and Engineering Contractors (P) Limited v. Chief Engineer, National Highways, Chennai
2025-01-09
L.VICTORIA GOWRI
body2025
DigiLaw.ai
ORDER : 1. This writ petition has been filed to quash the consolidated completion certificate dated 14.07.2022 issued by the third respondent and consequently directing the third respondent to issue work completion certificate with respective work completed dated i.e., 09.11.2020 and 27.02.2022. 2. The claim of the petitioner is that under the Annual Plan 2018-19, the work of strengthening in Km 599/0-633/0 in selected stretches of NH-47 including the widening of existing two lane at Km 625/0 - 626/2 into double Lane with paved shoulders of NH47 in the State of Tamil Nadu on Engineering, Procurement & Construction on EPC mode was awarded to the petitioner as per agreement dated 11.11.2019 and the appointment date was fixed on 20.11.2019. As per the agreement between the petitioner as well as the third respondent, the petitioner company commenced work and Bituminous Concrete (Wearing coat) work were completed for the reaches Km 607/0 – 610/100, Km 623/0 – 626/187, Km 630/0 – 630/546 and Km 631/660 – 632/520 of HN4 on 29.10.2020. The work of balance stretches from Km 610/100 – 620/0 and Km 631/0 – 639/0 of NH47 was stopped as per the Letter No.AP 883 / 20-18-2019 / A1 / dated 10.08.2020 due to laying of pipeline work by Divisional Engineer, National Highways, Nagercoil. After completion of the TWAD Board works, the petitioner resumed the road work on 16.09.2021 and completed the balance works in all respects on 03.03.2022 and a consolidated completion certificate was issued on 14.07.2022. Challenging the same, this writ petition is filed. 3. The plight of the petitioner as submitted by the learned counsel appearing for the petitioner is that the entire work was done in two phases and that the first phase of work was over on 20.09.2020. The petitioner company is bound to maintain the road for a period of five years from the date of completion in terms of agreement entered into between the petitioner company and the third respondent. The second phase of work was completed on 03.03.2022 and in terms of the said agreement, the petitioner is entitled to maintain both the stretch of roads in the first phase of work for a period of five years from 30.10.2020 and the second phase of work commencing from 04.03.2022.
The second phase of work was completed on 03.03.2022 and in terms of the said agreement, the petitioner is entitled to maintain both the stretch of roads in the first phase of work for a period of five years from 30.10.2020 and the second phase of work commencing from 04.03.2022. Since the consolidated completion certificate was issued only on 14.07.2022, the petitioner is in compulsion to maintain the entire stretch till 2027 which would be at his disadvantage causing him heavy loss. As per EPC mode, the maintenance period is only 5 years. The petitioner completed the first phase of work as early as on 29.10.2020 and the delay in completing the second phase of work could be attributed only to the third respondent. Only on the direction by Letter No.AP 883/2018-19/Al, dated 10.08.2020, the petitioner was in a compulsion to stall the work of the first phase and wait till the TWAD board work was completed, as directed by the third respondent. For clarity, the same is extracted as follows: Since the petitioner was not able to complete the second phase that is, the entire work in a single strength, the reason which is attributed only to the third respondent, the petitioner cannot be compelled to maintain the entire stretch till 2027 and hence, the petitioner is before me. 4. Mr.S.Kameswaran, learned Government Advocate based on his counter affidavit submitted that, as per the agreement entered into between the petitioner as well as the third respondent, the entire work was completed only on 27.02.2022. The work was completed physically only on 03.03.2022 but the same would be considered to be completed only after getting all the test results successfully. He further insisted that in terms of contract condition Article 14.1 (i) maintenance obligations of the contractor would be to maintain the Project Highway for a period of five years corresponding to the defect liability period, commencing from the date of completion certificate (Maintenance Period). 5. Heard the learned counsel on either side and carefully perused the entire materials available on record. 6. The learned counsel appearing for the petitioner forcefully argued that the test results would be taken by the respondents as and when the various works of the road were completed.
5. Heard the learned counsel on either side and carefully perused the entire materials available on record. 6. The learned counsel appearing for the petitioner forcefully argued that the test results would be taken by the respondents as and when the various works of the road were completed. No doubt in the instant case, the petitioner was compelled to stop his work in the midway only at the instance of the letter of the Divisional Engineer, Nagercoil dated 10.08.2020 for the purpose of completing TWAD board work in the same stretch of road. Hence, it is needless to state that by the activity of the third respondent the work which was undertaken by the petitioner as a single stretch was automatically converted into one of two stretches that to be completed in two phases. It can be understood from the mode of operation of the third respondent that they would have taken the test results work completed in the first phase on 29.10.2020 when the petitioner completed the same at the first instance. If they had not done that the said road would not have been dedicated for public use as conducted by the learned counsel for the petitioner. Having put the same for public use, I can positively assume that the third respondent had completed the test results for the said stretch as early as on 29.10.2020. Hence, the third respondent ought to have issued him with work completion certificate for the first phase of work at least by the month of October 2020. As far as the second phase of work is concerned, even according to the counter affidavit of the third respondent, the same was completed on 03.03.2022. There was no quarrel for the petitioner for awarding the said completion certificate even after the lapse of four months from 03.03.2022 and 14.07.2022 for the work completed in the second phase. 7. In view of the same, the impugned completion certificate dated 14.07.2022 is hereby quashed and the third respondent is directed to issue two completion certificates. One for the first phase of work on the basis of the tests results taken by the third respondent as early as during October 2020 facilitating him to maintain road work from 30.10.2020 for a period of five years.
One for the first phase of work on the basis of the tests results taken by the third respondent as early as during October 2020 facilitating him to maintain road work from 30.10.2020 for a period of five years. The impugned completion certificate set aside is only with respect to the first phase of work and this Court hereby direct to issue completion certificate only for the first phase of work. 8. This writ petition is partly allowed. There shall be no order as to costs. Consequently, connected miscellaneous petition is closed.